Providing Expert Solutions For Projects Worldwide

Providing Expert Solutions For Projects Worldwide

Phone: (610) 640-9600

Fax: (484) 301-0969

Case Stresses Importance

Case Stresses Importance

Court Has No Jurisdiction Over a Contractor Claim that Was Based on an Issue Raised to the Contracting Officer for Final Determination but Not Sufficiently Detailed and Explained; Notice Provisions Enforced Against Contractor, and Liquidated Damages Held to be Enforceable

Written by Gail S. Kelley, P.E., J.D.
Reprinted from ConstructionRisk, LLC

Where a contractor amended its complaint in an action against the United States to include a claim for remission of liquidated damages on the basis that it was entitled to a time extension, but the contractor did not explain why it was entitled to a time extension in its original letter to the contracting officer, the court had no jurisdiction over the claim. The contractor’s original letter did not contain sufficient details to establish a claim for an extension of time; the contractor could not cure this defect by sending a second letter to the contracting officer after litigation had begun. K-Con Bldg. Systems, Inc. v. U.S., 778 F.3d 1000 (2015).

Background

This dispute arose from a contract with the Coast Guard to construct a support team building in Port Huron, Michigan. The contract, which was for $582,64, included liquidated damages of $589 for each day of delay in completion. The Coast Guard accepted the building as substantially complete on May 23, 2005, but withheld $109,554 as liquidated damages for 186 days of delay. The contractor, K–Con, subsequently sent a letter to the contracting officer requesting remission of the liquidated damages, asserting that the “liquidated damages constituted an impermissible penalty” and the Coast Guard “failed to issue extensions to the completion date as a result of changes to the contract.” However, KCon provided no details regarding its request for time extensions.

When the contracting officer denied K–Con’s request for remission, K– Con sued in the Court of Federal Claims under the Contract Disputes Act (CDA). K–Con sought remission of the $109,554 in liquidated damages plus interest; it also requested additional compensation based on work performed in response to government requests that it alleged amounted to contract changes

After litigation had begun, K–Con submitted a second letter to the contracting officer. This second letter detailed the contract changes allegedly made by the Coast Guard and asked for a new remedy— $196,126.38 for additional work necessitated by the changes—and an extension of the completion date of the contract. When the contracting officer denied K–Con’s requests, K–Con amended its complaint in the Court of Federal Claims to add these allegations and to seek, in addition to the liquidated-damages relief, a judgment of $196,126.38 and a 186– day extension.

The Construction ADR Summit ABA Construction Forum, Austin, TX
October 8-9, 2015

MDCSystems® joined distinguished colleagues at the American Bar Association (ABA) Forum on the Construction Industry’s Fall Meeting in Austin, TX. MDC’s exhibit was a central location to discuss alternate dispute resolution (ADR), pick up company information or just to say hello. Other visitors left their business card at our booth for a chance to win the MDC cooler filled with goodies.

Everything from an examination of the new appellate rules of arbitration issued by AAA, drafting arbitration clauses that work, the business of being an ADR neutral and other topics were presented by leading lawyers and neutrals from around the country.

Related Posts

Once Upon a Time in Construction: When Promises Fall Apart

Once Upon a Time in Construction: When Promises Fall Apart

Our client was distraught and blurted out “ they said it would work” and now we have to demolish it. How did this happen? During the mid-90’s it was feared by the EPA that landfills would soon be at capacity to accept sewage sluge and the EPA had recently banned ocean...

read more
MDCSystems® Taking Off with Commercial Drones

MDCSystems® Taking Off with Commercial Drones

MDCSystems® has recently entered the commercial drone industry with its drone for various inspection and engineering evaluation services. The future for the commercial drone industry looks very bright. In 2015 the U.S. commercial drone market size was an estimated...

read more
Change Orders: Maximizing Benefits for Owners

Change Orders: Maximizing Benefits for Owners

Ronald F. Parisi, P.E.
Former MDC Systems® Project Director

Owners involved in ongoing construction projects are virtually unanimous in recognizing the need to minimize the number and amount of change orders as a way to keep the project costs within budget. In viewing change orders with only this in mind, however, owners may tend to overlook the benefits that the change order process offers to owners. The primary benefits afforded by the change order process are that it allows owners the flexibility to respond quickly, to capitalize upon opportunities and to mitigate problems — both of which frequently arise during the course of construction.

Continue Reading

read more

0 Comments